关于英文合同四篇
随着法律法规不断完善，人们越发重视合同，越来越多的人通过合同来调和民事关系，合同是企业发展中一个非常重要的因素。那么正式、规范的合同是什么样的呢？以下是小编为大家收集的英文合同4篇，希望对大家有所帮助。
英文合同 篇1
Employer: ___________ construction co., LTD. (hereinafter referred to as party a)
Contractor: _______________________________(hereinafter referred to as party b)
In accordance with the contract law of the People's Republic of China, the construction law of the People's Republic of China and the interim provisions on the administration of labor contract administration of project projects. Party a decided to ________________ company alarm project subcontracting to party b department, to standardize the management, clear responsibility, agreed by both parties, this contract is made, to abide by.
1. The contents of labor construction projects contracted by party a to party b are as follows:
All bricks, stone masonry and plastering projects in the construction blueprint of the project; Rebar production and binding sub-projects; Template making and installation of sub-projects; Scaffolding works.
Ii. Term of this contract:
From the beginning of ___________ to _______ _______ _______.
Iii. Engineering quality standard:
The quality of all itemized projects is assured.
Iv. Payment and payment method of labor management fee:
1, turned over standard: the labor service project management fee RMB $ten thousand, paid by party b, party b can achieve according to the contract that the project department and construction quality, progress of the requirements of party a according to the management fee of _____ % back to party b as a reward.
Payment method: payment of service fee shall be paid in two installments, that is, 50% before the main body is finished and 50% before the decoration is completed.
V. responsibilities of party b.
1. Party b shall provide relevant documents and qualifications and cooperate with party b to handle relevant procedures.
To coordinate labor disputes and industrial accidents during construction.
Vi. Responsibilities of party b:
1, I am grateful to fully perform __________________ company and construction co., LTD. The project construction contract signed. And shall bear all the responsibilities and obligations of party b in the contract.
2. Ensure the quality, progress and safety of all sub-projects to meet the contract requirements signed by the project department and the construction party. If not, it will be punished by 50% of the management fee.
Vii. Matters not covered herein shall be negotiated by both parties, and the supplementary provisions may be signed by the parties hereto, which shall have the same legal effect as this contract.
Viii. This contract is made in six originals, with each party holding three copies. The contract shall be executed by both parties and shall be completed upon completion of the project.
Party a: _______________________ party b: ________________________
Party a's representative: __________________ party b's representative: __________________.
中文版
发包方：___________建筑施工有限责任公司(以下简称甲方)
承包方：_______________________________(以下简称乙方)
依照《中华人民共和国合同法》、《中华人民共和国建筑法》及公司《关于工程项目劳务承包管理暂行规定》。甲方决定将________________公司______________工程项目部的劳务分包给乙方，为规范管理，明确职责，经双方协商一致，特签订本合同，以资共同遵守。
一、甲方发包给乙方的劳务施工项目内容范围如下：
该工程项目施工蓝图中所有砖、石砌筑及抹灰分项工程;钢筋制作、绑扎分项工程;模板制作、安装分项工程;脚手架搭设作业。
二、本合同期限：
从______年_____月起至___________年_______月止。
三、工程质量标准：
所有分项工程质量确保优良
四、劳务管理费的上缴及付款方式：
1、上缴标准：该工程项目劳务管理费为人民币壹拾万元整，由乙方上缴，如乙方能达到按该项目部与建设方所签订的合同中的质量、进度要求，则甲方按管理费的____ %返回乙方作为奖励。
付款方式：上缴劳务管理费按两次付清，即主体完工前付50%，装修完工前付50%。
五、乙方的职责
1、乙方提供相关的'证件及资质，配合乙方办理相关手续。
协调处理施工过程中的劳务纠纷及工伤事故。
六、乙方的职责：
1、全面履行__________________公司与_________________-建筑施工有限责任公司签订的项目施工合同。并承担该合同条款中乙方应承担的全部责任与义务。
2、确保所有分项工程的质量、进度、安全达到项目部与建设方签订的合同要求。如达不到则按管理费的50%进行处罚。
七、本合同未尽事宜，双方通过协商，可另签订补充条款，与本合同具有同等法律效力。
八、本合同一式六份，甲乙双方各执三份，经双方签字生效，至工程完工，双方结清劳务管理费后失效。
甲方：_______________________乙方：________________________
甲方代表：__________________ 乙方代表：__________________
英文合同 篇2
Labor Contract for Internship
甲方（用人单位）： 代理人：
Party A (Employer):
Authorized Agent：乙方（实习生）： Alex
居民身份证号码：
ID Number:
为明确实习学生与实习单位的责任与义务，经甲、乙双方协商，在自愿、平等、公平的基础上，一致同意签订本协议。
The contract is hereby concluded by both parties to definite each other’s responsibilities, in the principles of fairness, legitimacy, equality, voluntariness, consensus through negotiation and good faith.
一、协议期限 Contract Term
本协议自_20xx_年__04__月__27__日起至__20xx___年___04__月____28___日止。
二、实习岗位 Job Responsibilities
甲方根据乙方的实际情况和工作需要，安排实习学生在 英文编辑 岗位实习，乙方应按公司的工作要求，努力完成实习任务。 in accordance with both parties’ need and arrangement. Party B shall fulfill his job according to company’s business requirement.
三、实习补贴 Labor Remuneration
依照按劳取酬的原则，按甲方现行制度确定实习生的`实习补贴。具体支付方法如下：实习补贴 12 美元/小时，其他奖励: 根据实习生在岗工作表现而定 。
Party A shall pay off salary to Party B in accordance with current salary system and regulation:
四、工作时间及休息假日 Working Hours and Resting Hours
1、每周工作10小时；
1. Party B shall work for 10 hours a week.
2、每小时英文文章修改量不低于1000字；
2. Party B shall review English essays with more than 1000 words per hour.
五、合同解除、变更、终止 Revocation and Termination of Labour Contracts
1、经甲乙双方协商同意，本协议可以变更或解除；
1. The contract could be revoked upon agreement between the parties hereto.
2、乙方在本合同履行期间可以在说明原因的情况下向甲方提出终止实习合同，但必须提前1个月通知甲方，并作好工作交接，否则应承担相关责任。
2. Party B cannot suspend the contract during the period of validity unless he informs Party A and explains the reason 1 month in advance and arranges the handing-over, or Party B shall take the responsibility of any loss of Party A.
3、实习期间，乙方无法达到实习岗位工作要求甚至对甲方项目等造成损失或的，甲方有权单方面终止实习生劳动合同，并保留追究法律责任的权益。
3. Party A has the right to suspend the contract if Party B can not meet the demand of the job,even causes loss for Party A. Party A reserves the rights to investigate for legal responsibility
六、法律效力 Miscellaneous
本合同正本一式两份，双方各执一份，经甲乙双方签字后生效。
The contract is in duplicate, held by Party A and Party B respectively. The contract comes into effect upon signatures or seals of both parties.
甲方（签章）： 乙方（签字）：
Party A (Signature and seal): Party B (Signature):日期： 年 月 日日期： 年 月 日
Date: Date:
英文合同 篇3
编号： No：
日期： Date ：
签约地点： Signed at：
卖方：Sellers：
地址：Address： 邮政编码：Postal Code：
电话：Tel： 传真：Fax：
买方：Buyers：
地址：Address： 邮政编码：Postal Code：
电话：Tel： 传真：Fax：
买卖双方同意按下列条款由卖方出售，买方购进下列货物：
The sellers agrees to sell and the buyer agrees to buy the undermentioned goods on the terms and conditions stated below：
1 货号 Article No.
2 品名及规格 Description&Specification
3 数量 Quantity
4 单价 Unit Price
5 总值：
数量及总值均有_____%的增减，由卖方决定。
Total Amount
With _____% more or less both in amount and quantity allowed at the sellers option.
6 生产国和制造厂家 Country of Origin and Manufacturer
7 包装： Packing：
8 唛头： Shipping Marks：
9 装运期限：Time of Shipment：
10 装运口岸：Port of Loading：
11 目的口岸：Port of Destination：
12 保险：由卖方按发票全额110%投保至_____为止的_____险。
Insurance：To be effected by buyers for 110% of full invoice value covering _____ up to _____ only.
13 付款条件：
买方须于_____年_____月_____日将保兑的，不可撤销的，可转让可分割的即期信用证开到卖方。 信用证议付有效期延至上列装运期后15天在中国到期，该信用证中必须注明允许分运及转运。
Payment：
By confirmed， irrevocable， transferable and divisible L/C to be available by sight draft to reach the sellers before ___/___/_____ and to remain valid for ingotiation in China until 15 days after the aforesaid time of shipment. Tje L/C must specify that transhipment and partial shipments are allowed.
14 单据：Documents：
15 装运条件：Terms of Shipment：
16 品质与数量、重量的异义与索赔：Quality/Quantity Discrepancy and Claim：
17 人力不可抗拒因素：
由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责任。但是，受不可抗力事件影响的一方须尽快将发生的`事件通知另一方，并在不可抗力事件发生15天内将有关机构出具的不可抗力事件的证明寄交对方。
Force Majeure：
Either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood， fire， earthquake， draught， war or any other events which could not be predicted， controlled， avoided or overcome by the relative party. However， the party affected by the event of Force Majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.
18 仲裁：
在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商未能达成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会决定是终局的，对双方均有约束力。仲裁费用，除另有规定外，由败诉一方负担。
Arbitration
All disputes arising from the execution of this agreement shall be settled through friendly consultations. In case no settlement can be reached， the case in dispute shall then be submitted to the Foreign Trad Arbitration Commission of the China Council for the Promotion of International Trade for Arbitration in accordance with its Provisional Rules of Procedure. The decesion made by this commission shall be regarded as final and binding upon both parties. Arbitration fees shall be borne by the losing party， unless otherwise awarded.
19 备注：Remark：
卖方：Sellers： 买方：Buyers：
签字：Signature： 签字：Signature：
销售合同ＳＡＬＥＳ ＣＯＮＴＲＡＣＴ
日期： 合同号码：
Date： Contract No.：
买 方： （The Buyers） 卖方： （The Sellers）
兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：
This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter：
（1） 商品名称：
Name of Commodity：
（2） 数 量：
Quantity：
（3） 单 价：
Unit price：
（4） 总 值：
Total Value：
（5） 包 装：
Packing：
（6） 生产国别：
Country of Origin ：
（7） 支付条款：
Terms of Payment：
（8） 保 险：
insurance：
（9） 装运期限：
Time of Shipment：
（10） 起 运 港：
Port of Lading：
（11） 目 的 港：
Port of Destination：
（12）索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方 责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
Claims：
Within 45 days after the arrival of the goods at the destination， should the quality， Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable， the Buyers shall， have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers
（13）不可抗力：由于人力不可抗力的原由发生在制造，装载或运输的过程中导致卖方延期交货或不 能交货者，卖方可免除责任，在不可抗力发生后，卖方须立即电告买方及在14天内以 空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽 快发货。
Force Majeure ：
The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure， which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after 。 the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers， however， are still under the obligation to take all necessary measures to hasten the deliveryof the goods.
（14）仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提 交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。
Arbitration ：
All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached， the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission 。 the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.
买方： 卖方：
-------------------- ---------------------
（授权签字） （授权签字）
英文合同 篇4
Compensation Trade Contract
This contract is hereby made and entered into between Guangdong Jiaxing Industrial Co.,Ltd.(hereinafter referred to as Party A) and Tailong Electronics(Singapore) Co., Ltd.(hereinafter referred to as Party B) on October 12,1995 in Guangzhou, China on the basis of equality and mutual benefit and through amicable consultation.
Party A: Guangdong Jiaxing Industrial Co., Ltd.
Add:317 Huanshi East Road,Guangzhou,China
Tel: (020) 87786162
Fax: (020) 87619503
Party B: Tailong Electronics (Singapore) Co., Ltd.
Add:111North Bridge Road,Singapore
Tel: (65) 3324951
Fax: (65) 3324928
1. Contents of Transactions
1.1 Party A agrees to buy from Party B and Party B agrees to sell to Party A Assembly Lines for Color TV Sets, whose specifications, technical requirements, price and delivery schedule shall be specified in an additional contract to be made between both parties, which shall serve as an integral part of this contract.
1.2 Party B shall buy from Party A Color TV Sets turned out on the Assembly Lines supplied by Party B in an amount approximately equal to that of the Assembly Lines. The quality, quantity, unit price, packing and delivery schedule shall also be specified in an additional contract, which shall constitute an integral part of this contract.
2. Terms of Payment
Payment of the transactions stipulated in Article 1 shall be effected by reciprocal Ls/C. Party A shall open a usance L/C in favor of Party B to pay by installments the entire cost of the Assembly Lines to be supplied by Party B； whereas Party B shall open a sight L/C in favor of Party A to pay each shipment of Color TV Sets to be delivered by Party A. The tenor of the usance L/C shall be in consistence with the term of compensation stipulated in Article 3. The total proceeds received by Party A from selling Color TV Sets to Party B within the duration of this contract shall be equal to, and used to cover, the total value of the Assembly Lines. In case the total proceeds received by Party A from selling Color TV Sets to Party B is not enough to cover the total value of the Assembly Lines, the balance shall be made up by Party B with down payment before the usance L/C opened by Party A expires, thus enabling Party A to effect payment due under the usance L/C.
3. Term of Compensation
Party A shall pay the total cost of the Assembly Lines by exporting Color TV Sets to Party B within 10 months from the 4th month after all parts of the Assembly Lines are delivered. In principle, the amount to be paid by Party B for its imports from Party A per month shall be 10 percent of the total amount due to be paid for the Assembly Lines. Party A can make payment ahead of schedule with a notice to Party B 1 months in advance.
4. Currency for Pricing
Both the Assembly Lines and the Color TV Sets shall be priced in terms of US Dollars. If the Color TV Sets are also to be sold on the home market within the term of compensation and thus have a price in RMB, their export price shall be its equivalent in US Dollars according to the exchange rate then prevailing.
5. Interest Rate
Party A shall bear the interest on the usance L/C and the down payment of Party B. The annual interest rate is agreed up on at 7.5%.
6. Technical Service
After arrival at the destination, the Assembly Lines shall be installed by Party A. When Party A believes it is necessary, Party B shall send its technicians to provide on-the-spot instructions and other technical assistance in the course of installation. Party B shall be liable for expenses of the technicians and losses incurred in the course of installation as a result of technical default on its part.
7. Insurance
7.1 The buying and selling of the Assembly Lines and the Color TV Sets shall be on FOB basis, thus the ocean marine cargo insurance on them shall be effected by Party A and Party B respectively.
7.2 In the duration of this contract, the Assembly Lines shall be insured by Party A. Should any loss or damage occur, Party A shall lodge claims against the insurer and pay a part of the indemnification received from the insurer to Party B, which shall be in proportion to the payment Party A has not made for the part of machinery involved in the loss or damage.
8. Liability for Breach
Either party shall be liable for its breach of contract and indemnify for all losses thus incurred to the other party. In addition, the breaching party shall pay to the other party a fine, which shall account for 15% of the total amount involved.
9. Performance Guarantee
To guarantee the implementation of the contract, each party shall submit to the other a performance guarantee issued by a bank agreed by both parties. The guarantee bank of Party A is The Bank of China, Guangzhou Branch, while that of Party B is Sanwa Bank.
10. Force Majeure
10.1 Either party shall not be held responsible for failure or delay to perform all or any part of the contract due to flood, fire, earthquake, draught, war or any other events which could not be predicted at the time of conclusion of this contract, and could not be controlled, avoided or overcome by the relative party. However, the party affected by the event of Force Majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days of its occurrence.
10.2 If the event of Force Majeure lasts over 120 days, both parties shall have the right to terminate the contract.
11. Arbitration
11.1All disputes arising from the performance of this contract shall be settled through friendly negotiations. Should no settlement be reached through negotiation, the case shall then be submitted for arbitration to the China International Economic and Trade Arbitration Commission (Beijing) and the rules of this Commission shall be applied. The award of the arbitration shall be final and binding upon both parties. The arbitration fee shall be borne by the losing party unless otherwise awarded by the commission.
11.2 During the course of the arbitration, the contract shall be performed except for the part under arbitration.
12. Amendment to the Contract
The contract can be amended only after the amendment is agreed upon by both parties.
13. Language and Validity
13.1 The contract shall be written in Chinese and English. Both versions are equally authentic. In the event of any discrepancy between the two versions, the Chinese version shall prevail.
13.2 The contract shall come into effect as soon as it is duly signed by both parties and shall remain effective for two years.
Party A: Guangdong Jiaxing Industrial Co., Ltd
(Signature)
Party B: Tailong Electronics (Singapore) Co., Ltd
(Signature)
【英文合同】相关文章：
英文合同06-30
关于英文合同07-27
英文翻译合同03-02
【推荐】英文合同4篇04-26
英文合同合集10篇04-26
关于英文合同4篇04-24
英文合同集合8篇04-29
【精品】英文合同四篇05-03
有关英文合同四篇04-27
实用的英文合同4篇04-28